Private Law 75–175

That the claim of

Grier-Lowrance Construction Company, Incorporated.

Claim of, referred to Court of Claims.

Grier-Lowrance Construction Company, Incorporated, for losses and damages under contract numbered AMB 28, dated May 18, 1929, for the construction of the foundation for the several structures or the Arlington Memorial Bridge project be, and the same is hereby, referred to the United States Court of Claims with jurisdiction to hear the same to judgment, said claim to be adjudicated upon the basis of all losses or damages suffered by the said company duly found to be due to acts of the Government or delays caused by the Government or subsurface conditions unknown to the contractor and not disclosed by the Government before contract was entered into, notwithstanding any lapse of time or any provisions of the statute of limitations: Provided, That suit hereunder is instituted

Proviso.

Commencement of suit.

within four months from the approval of this Act.